避免施工索賠和糾紛需要對合同條款有更為深入的理解,很多施工索賠問題的發(fā)生都是由于早期沒有有效的溝通,沒有了解索賠的原因。謝麗爾·英普爾,弗朗西斯,哈特曼和喬治細(xì)細(xì)分析了施工合同中的一些關(guān)鍵要素,并深入調(diào)查了索賠的原因、補償索賠的索賠類別,并援引相同合同條款研究高層公寓大樓和機(jī)構(gòu)的建筑相關(guān)問題。
施工合同是確定當(dāng)事人之間的關(guān)系的基礎(chǔ)。合同是一種承諾或協(xié)議,是法律的強制實施。施工合同是長且復(fù)雜的文檔類型,因此,對于合同義務(wù)或期望可能產(chǎn)生分歧或爭議,當(dāng)一方覺得他們義務(wù)或期望在合同中沒有得到滿足,他們就不會認(rèn)同,他們認(rèn)為他們提交的索賠應(yīng)該得到貨幣或時間補償。索賠被定義為一個定論,以使客戶得到補救、救濟(jì)或財產(chǎn)補償?shù)臋?quán)利,
Literature Review on contractual issues arising claims
Avoiding construction claims and disputes requires understanding of the contractual terms, early no adversarial communication, and understanding of causes of claims.(Cheryl Semple, Francis T. Hartman, and George Jergeas) identify some of the critical element in construction contract, and investigates the causes of claims, categories of compensation of claims and contract clauses quoted in claims by studying high-rise apartment building and institutional buildings.
Construction contract determines the basis for the relationship between the parties involved in it. A contract is a promise or agreement that the law will enforce. Construction contract are very often long, complex document, consequently, disagreement or disputes can arise regarding contractual obligations or expectations, when one party feels that the contractual obligations or expectations have not been meet and they fell that they deserve monetary and/or time compensation they may submit a claim. A claim is defined as an assertation to the right to remedy, relief or property (Canadian Law Directory)
Currently construction industry in UAE has number of disputes arrives because of disputed in legal document and poor coordination in general and particular condition of contract. UAE is fast growing country in terms of construction and lots of competition for getting the project because of that contractors are bidding less and claiming more amounts. A client tries to reduce the over all cost of project and contractors tries to get more profit and result is disputes arise.
Every claim submitted by the contractor puts presser on client and consequently it affect increasing property price. That is why construction claim are considered as the most unpleasant event in construction industry. Claims can be reduced by proper arrangement of scope of work in contract document. Contract is the document which explains all rolls and liabilities of the parties involved in it. For the purpose of study for analyzing contractual issues literature review is divided in two parts. First part will discuss on Contract law in general and particular terms used in formation of construction contract. Second chapter will discuss on Claims under FIDIC contract and previous research in claims.#p#分頁標(biāo)題#e#
1 Introduction to contract law
1.1 Legal systems
A legal system, is a system for identifying factual situations where the state will impose sanctions on a person (criminal law), where one person can seek redress from another person (civil law), and where a person can challenge decisions of the state and public bodies, such as local authorities (administrative law)1. For example: If someone takes property belonging to another with the intention of permanently depriving them of that property, this is categorized by the criminal law as a crime (theft) for which the state can seek an order for imprisonment, a fine or both.
The same conduct is categorized by the civil law as a tort (known as conversion) for which the person whose property is taken can seek an order requiring the person taking the property to return it, to pay compensation (damages), or both. If the property is taken by the state or a public body in wrongful exercise of a statutory or other power, the decision to do so can be challenged in administrative law by seeking a declaration that it is invalid and should be reconsidered.
1.2 Criminal, civil and administrative law
The criminal law is principally concerned with the imposition of fines and imprisonment sought by the state against persons. The civil law is concerned with awarding compensation and making orders in favor of one person against another. Administrative law is principally concerned with making orders concerning the administrative actions of the state and public bodies.
1.3 Obtaining redress
The usual means of obtaining redress is in a court of law. The criminal courts, primarily the Magistrates' Courts and the Crown Court, are concerned with redress in respect of criminal matters .The civil courts, primarily the County Courts and the High Court, are concerned with redress regarding civil claims. In many countries, a separate court is established to deal with claims concerning the administrative actions of the state and public bodies, but this is not the case in everywhere, where administrative law matters are dealt with by the High Court. The courts are not the only means of obtaining redress in many civil matters.
1.4 The civil law of obligations
Each of the principal divisions of law - criminal law, civil law and administrative law - contains numerous subdivisions. The subdivision that is relevant to this publication, and to the series of which it forms part, is that part of the civil law concerned with the law of obligations.
1.5 Obligations in contract and tort
The law of obligations has, in turn, two parts: the law of contract and the law of torts. In the law of contract, a person's obligations are primarily founded on agreement and are, in general, owed only to the other party to the agreement, not to persons generally. Because obligations owed in contract are founded on agreement, they can be as prescriptive and detailed as the parties wish and their agreement requires. For example, agreed obligations can concern the development of an office block in accordance with detailed requirements, or the structuring of a long-term business relationship, such as a partnership.#p#分頁標(biāo)題#e#
It would be impossible to regulate such relationships using only the law of torts, since obligations in tort are too generalized. In the law of torts, a person's obligations are primarily determined by general principles of law and are, ordinarily, owed to persons generally. Since obligations owed in tort are imposed as part of the general law, they are expressed in the form of general standards of conduct. For example: the obligation to exercise reasonable skill and care so as not to cause injury or damage to others forms the basis of the tort of negligence; the obligation not to unreasonably interfere with a person's use or enjoyment of their land forms the basis of the tort of nuisance. Both parts of the law of obligations are significant for the construction industry.
Work on a building project, such as the provision of consultant services, construction or materials, will ordinarily be carried out under a contract since this is the only way that obligations having the required definition and precision can be given legal force. But the work provided may, if defective, cause damage not only to the person with whom those obligations are agreed but to others, such as adjacent landowners, users and subsequent owners of the project. While the person or persons with whom the contract is made will, ordinarily, be able to seek redress in the law of contract, those who are not parties to that contract will have to seek redress in the law of torts.
The law of contract is of fundamental importance for the construction industry because the contract is the principal vehicle for those working on a project to be engaged, their obligations are regulated and redress assessed if things go wrong. The law of torts has a subsidiary importance if things do go wrong.
1.6 Rights and obligations
The law is often discussed in terms of obligations, there is, in general, for each obligation a corresponding right .Thus, an obligation not to unreasonably interfere with a person's use or enjoyment of land can be seen, from the perspective of a landowner, as a right to enjoy and use their land free from such unreasonable interference. An obligation to perform the terms of an agreement can be viewed from the other party's perspective as a right to have those obligations performed. In contract law, these rights and obligations are often referred to as the benefits and burdens of the contract.
1.7 Defining a contract
There are various definitions that attempt to encapsulate the essential nature of a contract. The definition that is most readily understandable in a commercial context is that a contract is an agreement that gives rise to obligations, and corresponding rights, that the law will recognize and enforce.
Since a contract is founded on agreement, the parties are free, within wide limits, to agree the obligations to which they wish to be bound. This is known as the doctrine of freedom of contract. It means, at any rate in a commercial context, that the parties to a contract will ordinarily be bound by the agreement they make, however inappropriate, one sided or even ruinous that agreement may turn out to be for one of them. The corollary of the doctrine of freedom of contract is that a person cannot be forced to contract. In a commercial context this means that, if terms cannot be agreed, either party to the negotiations can walk away, however inconvenient or costly, in terms of wasted time and money, this is for the other party. It may be possible to break off negotiations and walk away even if work has commenced in anticipation of a proposed contract.#p#分頁標(biāo)題#e#
Once a contract is concluded, it binds the parties in law. If a party to a contract fails to comply with its obligations under the contract, the other can seek redress for that failure. This can be done, as appropriate, by enforcing a right to payment (a claim in debt), by seeking financial compensation for losses suffered as a result of the failure (a claim in damages for breach of contract) or, in certain circumstances where financial compensation does not provide adequate redress, by an order that the defaulting party perform its obligations (a claim for specific performance) or stop acting in breach of its obligations (an injunction).
For example, if a consultant fails to perform services he or she has contracted to provide, the client can seek damages based on the additional cost of obtaining substitute performance from another consultant. If an employer fails to pay for work provided by a contractor, the contractor can recover that payment as a debt. If a person contracts to sell land, such as an office or house, but refuses to complete the sale, the purchaser can seek an order that the land be conveyed to it.
1.8 Categories of contract
The categories of contract is most relevant to the construction industry include the following.
Contracts made by deed and simple contracts (the rest). Contracts entered into by deed do not require consideration; simple contracts do. For example, a promise of a gift will be contractually binding only if it is given by deed. Contracts made by deed also attract a longer limitation period (the period during which proceedings for redress must ordinarily commence) than simple contracts. The period is 12 years from breach for contracts made by deed, 6 years from breach for simple contracts.
Contracts for estates or interests in land (such as a contract for the sale or lease of a house or office). Such contracts are governed by the Law of Property Acts and related legislation and by that branch of the law known as the law of real property. Most of such contracts are subject to the code for payment and dispute resolution provided for in that Act.
Arbitration agreements (an agreement that provides that disputes will be determined by a private tribunal sitting as arbitrator, not by the court). Such agreements are subject to the detailed code set out in the Arbitration Act 1996.
Consumer contracts (certain categories of contract, principally contracts for goods, for work and materials and for services where one of the parties is contracting for purposes that are outside the scope of its business, if any, and the other is contracting in the course of a business). Such contracts are subject to various statutory controls that may invalidate certain types of unfair or unreasonable terms imposed to the determent of the consumer.
1.9 The importance of contracts in the construction industry:#p#分頁標(biāo)題#e#
Contract is only the forming agreements that are recognized as binding by the law of contract that the parties can regulate their rights and obligations in the knowledge that these rights and obligations can, if necessary, be enforced. Given the importance of contract law in structuring commercial relations, it is surprising that those procuring and providing work in the construction industry often deal inadequately with the formation of their contracts. This leads not only to uncertainties about what was agreed and when, but also to disputes about whether a binding agreement was concluded at all and whether legally enforceable obligations are created to provide work or' to pay for it. Such disputes can arise during the work as well as after it is completed.
1.10 Contractual terms used in formation of contract
The obligations that the parties accept when they conclude a contract are contained in its terms. The terms may be express or implied or, more usually, a combination of both.
1.10.1 Express terms
Express terms are those that the parties expressly state when making their contract. Express terms may be written or oral. Oral terms may be evidenced in writing.
* Written terms set out in documents forming the contract - for example, where a client and builder execute a copy of a standard form building contract, such as a copy of the FIDIC condition of contract setting out all of the terms they have agreed, or where, as is often the case in a contract for the sale of goods, all of the terms are set out in a letter of offer, accepted by the purchaser orally or by conduct.
* Written terms contained in documents referred to (incorporated by reference) in the exchange of communications forming the contract
* Oral terms agreed at a meeting or over the telephone. It is preferable for oral terms to be recorded (evidenced) in writing so that there can be no dispute about what was said, for instance by making and circulating a note of what was agreed. But failure to do this will not affect the validity of such terms, unless the contract is of a type whose terms must be made or evidenced in writing.
1.10.2 Implied terms
Implied terms are those that are included in a contract even if the parties do not expressly refer to them at the time the contract is concluded.
* Contract terms are implied by law or by statute if the contract is of a type in which such terms are ordinarily implied and the implication of those terms is not contrary to the express terms of the contract. For example, terms are ordinarily implied by the Sale of Goods Acts into contracts for the sale of goods, and by the Supply of Goods and Services Acts and law into contracts for work and materials or for services.
* Terms implied to reflect the parties' presumed intention if, having regard to the words used in the contract and the circumstances at the time it was concluded, they are necessary to give business efficacy to the contract or are so obviously a part of the contract that both parties would, if asked at the time, have said that they go without saying. For example, a contract to use a wharf will be subject to an implied term that it is safe for the ship to lie at that wharf. But a term will not be implied on this basis if it is inconsistent with the express words of the contract.#p#分頁標(biāo)題#e#
* Terms may be implied by custom where the custom is a certain and general incident of a particular trade or place, and the use of the term is well known, reasonable and not contrary to law or to the express words of the contract.
* Contract terms implied by course of dealing where the parties have contracted on the same terms on a number of previous occasions and they make another contract of similar type without expressly referring to those terms.
1.10.3 Exemption clauses
An exemption clause is a contract term by which one party, usually but not invariably the party proposing the terms of contract, seeks to avoid or exempt itself from what would otherwise be its obligations or liability under the contract (an exclusion clause), or seeks to restrict or limit its liability in some way (a limitation clause).An exemption clause can work indirectly by, for instance, restricting the enforcement of obligations under a contract, or by making enforcement unusually onerous.
Exemption clauses are commonly found in standard terms of business. For example, a seller of goods may seek to limit its obligations by providing in its standard terms that they form the whole agreement of the parties, and no terms are to be implied at law. The purpose of such wording is to exclude the implied terms of quality and title that would otherwise apply to the contract. A consultant provides in its terms of appointment that any liability, whether for default under the contract or in negligence, is limited to a specific sum. The purpose of such a provision is to cap the consultant's potential liability to its client.
Because exemption clauses exclude or limit what would otherwise be a party's obligations or liabilities under a contract, they must be clearly incorporated and clearly worded if they are to be effective. There are also various statutory controls over the effectiveness of such provisions, and, in a few instances, criminal sanctions are imposed on those who seek to include such clauses in their contracts.
1.11 Most Commonly Used Types of contract in UAE construction industry
There are various types of conditions of contracts used all over the world. Most commonly used conditions of contracts in the past are FIDIC in Middle East & JCT & NEC in United Kingdom. In United Kingdom mainly JCT & NEC conditions of contract is in practice in various forms. The conditions of contracts are listing the legal structure to be refereed to in case of any dispute or ambiguity arises. It also establishes a common basis to both the contractor and the client in understanding each party's commitments and rights against the other party. Understanding the rights and obligations are important prior to the agreement of a contract between the parties.
1.12 Key contract clauses used in condition of contract#p#分頁標(biāo)題#e#
1.12.1 Audit -
This clause typically outlines an owner's right to perform reviews (audits) of contractor costs or records. Such clauses ordinarily outline what costs or records are subject to audit, when and under what circumstances. In cost plus contract this clause is very useful to client to restrict the overall project cost
1.12.2 Changes -
This clause is critical. This is the clause that allows the owner to direct changes to the work, including plans, specifications, and time of performance, means, and methods. Absent a change clause, an owner is precluded from making changes to the work. Of particular importance in this clause is whether the clause allows the owner to unilaterally direct changes to the work (in which case, if the contractor refuses to comply with the directives, they are in breach of the contract). Alternatively, the clause requires the owner and the contractor to mutually agree on the change (a bilateral change). On the other hand if there has been any discrepancy in specification or drawing this clause will help contractually to change this discrepancy with required adjustments. However changes can result positive or negative variation in construction industry.
1.12.3 Contractor Responsibilities -
This clause lays out, in general form, the duties, obligations and responsibilities of the contractor in performance of the work. This clause assigns specific risks to the contractor, including customarily the risk of adequate labor and equipment to accomplish the work within the required timeframe, the obligation to perform work safely, to perform work in strict accordance with the terms and conditions of the plans and specifications, and to be responsible for the work of subcontractors and suppliers, etc. This clause is very important in construction for client's points of view. As such client investing a large amount of money in the project so because of this clause he will get relief and guaranty for the works which has to be executed.
1.12.4 Delays -
This is, ordinarily, a risk allocation clause with respect to delays in the work. “Excusable delay” under a contract results in time extensions but no time related damages. That is, a contractor's performance time is extended because of excusable delay situation, but the contract is not entitled to collect time extension costs nor is the owner entitled to impose late completion damages for this time. “Compensable delay”, on the other hand, results in both a time extension as well a time excusable and compensable to the contractor while contractor caused delay is the responsibility of the contractor (to either make up the lost time or pay the contractually stipulate late completion damages). Third-party caused delay (sometimes referred to as force majeure delay) is, most often, excusable and no compensable to the contractor.#p#分頁標(biāo)題#e#
1.12.5 Differing Site Conditions or Changed Conditions -
This clause normally provides an equitable adjustment to the contract in the event the contractor encounters a materially different condition at the site during performance of the work. This is the clause which will give relief to the contractor when he will get differ in site condition e.g. Non stop rain for few month. Differing site conditions are unforcing events no one can predict these events. In this situation this clause is very important in construction industry to restrict unnecessary claims
1.12.6 Dispute Resolution -
This clause customarily sets forth the mechanism to resolve disputes during the performance of the work. Most dispute clauses contain some form of a stepped resolution system. For example, the clause may require on site negotiation between project managers, followed by an appeal to project executives, followed by 3 days of mediation, followed by binding arbitration under a formal set of rules. Often, the location (jurisdiction) of the disputes resolution will be set forth. In construction industry there are several methods of dispute resolution like negotiation, mediation, Conciliation natural evaluation, adjudication, arbitration, and litigation. However each of then having its own framework to resolve the dispute. These are the primary steps of resolving the the disputes on claims in construction industry.
1.12.7 Force Majeure -
Some contracts contain a force majeure clause or a clause dealing with delays to the work caused by unforeseeable events beyond the control of both the owner and the contractor. Such clauses often provide lists of examples of force majeure events - acts of God, acts of the government, civil disorder, acts of war, adverse weather, fires, floods, strikes, etc. Other contracts provide for such events in the excusable delay clause. In construction to get the relief to the parties involved in the contract from the unforeseen event. This will help to gain loss or expense due to unforeseen event.
1.12.8 Governing Law -
The contracts involve parties from differing locations with subcontractors and suppliers from even more locations. Accordingly, contracts often specify which law applies to a dispute, regardless of where the dispute is handled.
1.12.9 Indemnification -
To indemnify another is to protect them against loss or damage either by paying for the loss or standing in their place in the event of legal dispute. An indemnification clause in a contract typically requires a contractor to indemnify the owner against all loss resulting from contractor errors, omissions, accidents, third party property damages in construction industry.
1.12.10 Insurance -
This clause requiring the owners and contractors to furnish multiple insurance policies prior to commencing work, among which are the following: builder's risk/all risk; workman's compensation; automobile, aircraft, and/or marine liability; general liability; bodily injury; broad form property damage; completed operations; personal injury; etc. Generally in UAE construction industry Third party insurance and professional indemnity insurance are covered in the contract document.#p#分頁標(biāo)題#e#
1.12.11 Late Completion Damages -
This clause specifies the damages for late completion. In general terms, there are two types of late completion damages - actual and liquidated. Actual damages are those damages an owner actually suffers when a contract is completed late and may include loss of revenue, increased engineering, architectural or inspection services, increased financing costs etc. Liquidated damages, on the other hand, is a pre-agreed upon amount the contractor will pay the owner in the event the project is completed late due to no excusable delay cause-that is, due solely to the contractor's fault. Such damages are typically expressed in terms of a daily cost and need not be proven as actually incurred if the project is completed late.
1.12.12 Limitation of liability -
In order to cap (or limit) a contractor's risk from late completion damages, performance penalties, etc., under a contract, many contracts contain a clause limiting maximum liability to a percentage of the value of the contract. However this clause is very important UAE construction industry. UAE is fast growing country and maximum contracts are on lump-sum basis. Contractors have to bear all risk involved in the construction.
1.12.13 Order of Precedence -
This clause intended to provide guidance to both the owner and the contractor in the event of conflicting provisions. Typically, specifications have precedence over general provisions, and so on and so forth. The legal concept is to provide guidance to people on projects in the event there are two or more conflicting provisions relating to a topic. In UAE construction industry most preferable contract is FIDIC and the order of precedence used is Contract document, ant amendment to contract document, drawing, specification and Bill of Quantity. However if any disputes arises the above mentioned order is used to settle the disputes in construction
1.12.14 Owner Responsibilities -
Similar to a contractor responsibility clause, an owner responsibility clause ordinarily sets forth the obligations of the project owner, including adequate project financing, all required and necessary permits, appropriate site access, etc. These are the responsibilities covered in the contract document to run the project without any disturbance from the client/owner side. These clauses bound the owner in contractual framework to take any action during the execution of works
1.12.15 Payments -
This is key contract clause in terms of project cash flow. This clause sets forth how often the contractor is to be paid, in what manner, and what are the conditions precedents to the issuance of payment. In construction it helps the contractor to manage the finance before the commencement of project.
1.12.16 Quantity Variations -#p#分頁標(biāo)題#e#
The contracts contain estimated quantities to be installed. In the event as-bid quantity estimates vary substantially (+/- 10 percent or more) many contracts (both unit price and lump sum) contain a quantity variation clause which allows either the owner or the contractor to request a predetermination of the as-bid unit price on affected portions of the work.
1.12.17 Schedules -
A schedule clause typically sets forth the requirement for contractor scheduled , including format (bar chart vs. CPM), level of detail, submittal requirements, frequency of schedule updating, damages for failure to submit, delay or time extension analysis requirement, actions to be taken in the events of forecasted late schedule, etc.
1.12.18 Suspension of Work -
This clause habitually allows a project owner to suspend or stop all or some of the work, with or without clause. Such clauses normally provide for some adjustment to the terms of the contract in such events, including a time extension and payment of delay costs. However, recovery of time and cost limited by the terms of contract. Often, if the actual clause of the suspension order is something for which the contractor is responsible (i.e., unsafe work conditions, work not in compliance with contract requirement, etc.) no recovery time or cost is allowed. This clause gives the owner choice to delete the some or whole part of work with legal manner
1.12.19 Termination -
Almost all contracts have a provision allowing the owner to end, in whole or in part, performance of the work prior to project completion. There are, typically, two types of termination; termination for convenience and termination for default. Termination for convenience usually occurs when a project owner decides, for their own reasons, not to complete the project as designed. Such situations might arise if the owner's needs change, if project financing fails, or if the underlying project economics change substantially. In such a circumstance, the owner may elect to terminate the contractor's performance for the convenience of the owner and pay off the contractor in accordance with the terms of the clause.
Termination for default arises only when a contractor is found to be in material breach of the contract, has been provided with a cure notice form the owner outlining the material breach, and has failed to remedy the breach in a timely manner. Usually the owner will terminate the contractor from the project and call upon the contractor's financial guarantees to complete the work (i.e., letter of credit or surety bond). Some contracts also provide a contractor the right to terminate their participation in a project. Under certain carefully proscribed circumstances (such as, failure to make payments, bankruptcy of the owner, suspension of the work for more than a defined period of time, etc.) the contractor is allowed to terminate their own involvement in the project.#p#分頁標(biāo)題#e#
1.12.20 Time of the Essence/Time of Performance-
Timely project completion is normally important, most contracts contain a clause stating that “Time is of the essence of this contract. “Such a clause must be included to make enforceable a time of performance clause and collection of late completion damages. Absent such a clause, the time of project completion is considered unenforceable. The time of performance clause, typically expressed either in work or calendar days after issuance of notice to precede, sets froth when the work must be completed and the consequences of failure to meet these dates.
1.12.21 Warranty -
A warranty clause, which ordinarily continues in existence for some specified period of time after project completion, guarantees the contractor's work after project acceptance. It is not uncommon for warranty clauses to require a warranty for 1 year after project completion, during which time, if any portion of the project fails, the contractor is obligated to return to the project and make it right or agree to some commercial settlement of the issue.
1.13 Strengths and Weaknesses of contract in construction industry
Various advantages and disadvantages in the usage of contracts. The contracts are imposing a better control over the contractors and always state the penalties for non-compliance. Punishment used as a tool for guidance of the projects for timely completion and it is not working always successfully.
1.13.1 Strengths
* Firmly laid down rules and regulations
Rules and regulations are made up to follow the instruction in the same way contract provides rules and regulation for the parties. It provides instruction to the parties what should have to be done at each stage of the projects. Such as health and safety requirement in document for each construction project.
* Pre agreed procedural commitments
Contract includes the procedure which should have to follow by the parties involved in it. It provides what should be done by the parties in the initial stage of the project, during the execution of the project and after the completion of the project. It provides a complete framework for the parties which should have to follow to achieve the contractual goal by minimising the disputes and good quality product. E.g. provision of payment terms in the document.
* Better control over the contractor
Contract is a legally binding document which clearly specifies the roles and responsibility of the parties. Provisions like warranty, late completion damage, schedule in the contract puts pressure on contractor to be in line with the contract. This will avoid unnecessary delay and unnecessary claims in construction industry. E.g Provision of liquidation damage and penalty clauses.#p#分頁標(biāo)題#e#
* Pre defined dispute resolution techniques such as arbitration and amicable settlement
Disputes are common in construction industry. In the court of law it takes several months or several years to take the decision. To avoid this in construction alternative disputes resolution technique amended in the contract. After all it's a matter of money for one of the party and alternative dispute resolution is a quick method to resolve dispute. In UAE several techniques are used to resolve the disputes as stated above.
* Legal binding between both the parties with the signing of the agreement
After signing the agreement by the both parties contract is a legal document. Once the contract is awarded it other parties responsibility to complete the contract with required output. If any party fail to complete the contract the contract document will provide the remedy for the failure.
* Allocation of risks and responsibilities of each party
Construction includes technical and contractual risks. However these risks are for both parties involved in the contract. Contract provides the proper risk allocation and responsibilities for each party.
1.13.2 Weaknesses
* Ambiguities and misinterpretation
These are the human error occurred in the contract document. Lack of experience in drafting the contract document creates discrepancy and misrepresentation in the contract document. However it creates unnecessary claims in construction industry and ultimately affects the budget of client. E.g inefficient specification and drawings
* Misunderstanding and misleading
Inexperience contract administration and lack of knowledge in the subject of contract creates misunderstanding and misleading during the execution of project. The over all result creates claims from both sides of the parties involved in the contract.
* Unclear and complicated legal terms
These are the contractual terms used in contract. Most of the cases participant in the contract not able to get clear picture of complicated legal terms. For e.g. penalty clauses and liquidation damages clauses.
* Lengthy dispute resolution techniques
Disputes are closely related to money for each party. One will gain money and other will loos money. Provision of making dispute resolution in contract clearly specifies the time requirement for the technique used to resolve dispute. These techniques are time consuming technique and if both parties angry on it then only the result will come out other wise it will go to the court of law.
* Load the sole responsibility on the contractor
Most of the contract used in construction industry transfers maximum risk on contractor side. This is because of most of the clients are not aware of construction industry and they don't want to be involved in construction activities. Risk involves significance increase in cost of material, property damage and economic damage to the community, delay in project completion.#p#分頁標(biāo)題#e#
1.13.3 Practicability
The contracts are in practice traditionally over a long period, the parties consists awareness of application and acquaint to the system. When a contractor receives a tender to price, he even is not reading the conditions of contract because he has bighearted the same and overconfident. Due to this habit if any amendment made even in the particular application, it will be overlooked by the contractor. This negligence will lead to major disasters and the damage is realized during the progress of the works. There is no remedy, which is possible at this stage and the consequences are to be bared by the contractor.
1.13.4 Applicability and Coverage
Contracts are covering the full scope of the construction of a project. It is furnishing a fair coverage of the contractual issues normally appearing during the operational stage expects the complicated and irresolvable disputes when the contractor is in disagreement. It is a typical interpretation provided by the contracts and if the same is accepted by the contractor then it is resolved and concluded then and there it self.
The serious issues between the client and the contractor are referred to arbitration. This is a process of about one year and in a project spanning over a year of contract period this type of dispute resolution is disastrous. So it can be defined as the coverage of a condition of contract is only applicable for minor issues and not at all for major and complicated contractual issues. There fore it is important to seek for an alternative dispute resolution technique, which is more sustainable in addition to the conditions of contract in the contract administration of projects.
2 CLAIMS UNDER FIDIC CONDITION OF CONTRACT
2.1 Introduction
Claim is a legal action to obtain money or the enforcement of the right against another party. The legal document which carries claim is called statement of claims (Wikipedia). Contracts are playing a major role in construction claims. It is the law book, establishes the clauses relevant to various aspects for the post contract administrators to follow. When the contractors are submitting a claim, they have to refer to relevant contract clauses stated in the contract between the parties. Without the clause reference, the claims are invalidated. Therefore, it is a compulsory requirement for a project to have a, conditions of contract. Contract means a bilateral agreement between two or more parties made prior to commencement of works in a construction project.
Claims mainly generated by the contractor to the client. For employer claim reflect an increase in price for the project and for contractor it many be a source of further income from the project
2.2 Basis of claims in construction industry
Claims under the contract based on the certain event occur and culminant became entitle to a remedy specified under the particular provision of contract. Such event having two types first, it is specified event under the contract, which may or may not occur. Secondly, the specified events which are a breach of a particular stipulation in the contract entitling a claimant to a designated remedy if the provisions of such stipulation are not, or only partially, complied with#p#分頁標(biāo)題#e#
Claim arises out of the contract which is based on the grounds that a term of contract had been breached but the remedy is not designated. If the claim is valid, the remedy lies under the provision of the applicable law of contract.
Claim under the law of tort of the applicable law of the contract, based on the grounds of a specific legal rule or principle. If the claim is successful, the remedy lies in general in a 'just and equitable' award depending upon the particular circumstances of the case.
A claim where no contract exists between the parties, or, if one existed, is deemed to be void. It is based on the principle that an individual has the right to be paid a reasonable remuneration for work done.
Finally there is the ex gratia claim (out of kindness) where there is no legal basis but rather some commercial sense in making a settlement.
2.3 Generation of claims
Claims arise when contractor determines that they are entitled to payment to account for loss or expense they have incurred due to the action of other. Claims generated due to various reasons such as;
* Site conditions
* Variations and additional works
* Physical obstructions unforeseen by the contractor
* Adverse climatic conditions
* Delay in issuance of design drawings
* Change of nature of work
* Suspension of work
* Prevention by the client
* Breech of contract
* Possession of site
* Ambiguities of the contract
* Insufficiency of coverage
* Various other reasons
2.4 Contract clauses applicable to claims
In UAE mostly used conditions of contract FIDIC 4, 1987 edition amended to suit local conditions and most appropriate clauses related to claims are;
* Priority of contract documents (5.2)
* Notice of disruption of progress (6.3)
* Delays and cost of delay in issue of documents (6.4)
* Failure by contractor to submit documents (6.5)
* Permanent works designed by contractor (7.2)
* Contractor's general responsibilities (8.1)
* Claim under performance security (10.3)
* Sufficiency of tender (12.1)
* Adverse physical obstructions or conditions (12.2)
* Notices (12.3)
* Programme and cash flow (14)
* Care of work (20)
* Employer's risks (20.4)
* Contractor's risks (20.5)
* Fossils (27.1)
* Opportunities for other contractors (31.1)
* Facilities for other contractors (31.2)
* Materials, plant and workmanship (36)
* Uncovering and making openings (38.2)
* Removal of improper work, material and plant (39.1)
* Default of contractor in compliance (39.2)
* Suspension of work (40)#p#分頁標(biāo)題#e#
* Possession of site and access (42.1)
* Failure to give possession (42.2)
* Time for completion (43.1)
* Extension o0f time (44)
* Rate of progress (46.1)
* Penalty for delay (47)
* Taking-over certificate (48)
* Defects liability period (49)
* Contractor to search (50.1)
* Variations (51)
* Valuation of variations (52)
* Notice of claims (53.1)
* Contemporary records (53.2)
* Substantiation of claims (53.3)
* Failure to comply (53.4)
* Payment of claims (53.5)
* Correction of errors (55.2)
* Method of measurement (57.1)
* Breakdown of lump sum items (57.2)
* Provisional sums (58)
* Nominated sub-contractors (59)
* Monthly statements (60)
* Defects liability certificate (62.1)
* Default of contractor (63)
* Urgent remedial work (64.1)
* Special risks (65)
* Payment in the event of release of performance (66.1)
* Engineer's decision (67.1)
* Amicable settlement (67.2)
* Arbitration (67.3)
* Failure to comply with engineer's decision (67.4)
* Law an procedure (67.5)
* Default of employer (69.1)
* Contractor's entitlement to suspend work (69.4)
* Increase or decrease of cost (70)
The most frequent causes of delay according to owners, consultants and contractors are shown in Table - 1. From the owners point of view the most frequent causes of delay are related to both contractor and labors. And from the contractors point of view the delay of progress payment by the owner is one of the most server causes of delay. The most server causes of the delay as seen by the owner are as follows
* Storage of labors
* Unqualified work force
* Inadequate contractors experience
* Difficulties in financing the project by the contractor
* Ineffective planning and scheduling of project by contractor
* Low productivity level of labor
* Reworks due to error in construction
* Delay in progress due to late payment by owner
* Original contract duration is too short Similarly the most server causes of delay as seen by the consultant are as follows
* Difficulties in financing project by contractor.
* Inadequate contractor's experience.
* Shortage of labors.
* Delay in progress payments by owner.
* Delay in material delivery.
* Poor site management and supervision by contractor.
* Ineffective planning and scheduling of project by contractor.
* Type of project bidding and award.
* Poor qualification of the contractor's technical staff.
* Low productivity level of labors.
* Unqualified work force.
#p#分頁標(biāo)題#e#
When we considering claims most frequent and most disruptive claims is “Delays and time extension claims”. Time overrun claim can be divided in to three categories
1) Those over which neither party to the contract has any control
2) Those over which the construction owner has control
3) Those over which contractor has a control
Generally recognized that claim of type 1 are part of the contractor's normal and legitimate monetary risk, and hence should give neither party grounds for monetary recompense, but that the contractor completion date should be extended in order to protect contractor from liquidated damage claims from the late completion. Alternatively in the extreme a contract may be repudiated due to ‘frustration'. It is also recognized that for claim of type 2 the contractor should receive fair and recompense (cost and time), where as for type 3 claims the contractor is full responsible.
TABLE NO 1 - LIST OF CAUSES OF DELAY CATEGORISED IN GROUPS
No.
Causes of delay
Group
1 Original contract duration is too short
Project
2 Legal disputes b/w various parts
Project
3 Inadequate definition of substantial completion
Project
4 Ineffective delay penalties
Project
5 Type of construction contract (Turnkey, construction only,.)
Project
6 Type of project bidding and award (Negotiation, lowest bidder,.)
Project
7 Delay in progress payments by owner
Owner
8 Delay to furnish and deliver the site to the contractor by the owner
Owner
9 Change orders by owner during construction
Owner
10 Late in revising and approving design documents by owner
Owner
11 Delay in approving shop drawings and sample materials
Owner
12 Poor communication and coordination by owner and other parties
Owner
13 Slowness in decision making process by owner
Owner
14 Conflicts between joint- ownership of the project
Owner
15 Unavailability of incentives for contractor for finishing ahead of schedule
Owner
16 Suspension of work by owner
Owner
17 Difficulties in financing project by contractor
Contractor
18 Conflicts in sub-contractors schedule in execution of project
Contractor
19 Rework due to errors during construction
Contractor
20 Conflicts b/w contractor and other parties (Consultant and owner)
Contractor
21 Poor site management and supervision by contractor
Contractor
22 Poor communication and coordination by contractor with other parties
Contractor
23 Ineffective planning and scheduling of project by contractor#p#分頁標(biāo)題#e#
Contractor
24 Improper construction methods implemented by contractor
Contractor
25 Delays in sub-contractors work
Contractor
26 Inadequate contractor's work
Contractor
27 Frequent change of sub-contractors because of their inefficient work
Contractor
28 Poor qualification of the contractor's technical staff
Contractor
29 Delay in site mobilization
Contractor
30 Delay in performing inspection and testing by consultant
Consultant
31 Delay in approving major changes in the scope of work by consultant
Consultant
32 Inflexibility (rigidity) of Consultant
Consultant
33 Poor communication / coordination between consultant and other parties
Consultant
34 Late in reviewing and approving design documents by consultant
Consultant
35 Conflicts between consultant and design engineer
Consultant
36 Inadequate experience of consultant
Consultant
37 Mistakes and discrepancies in design documents
Design
38 Delays in producing design documents
Design
39 Unclear and inadequate details in drawing
Design
40 Complexity of project design
Design
41 Insufficient data collection and survey before design
Design
42 Misunderstanding of owner's requirements by design engineer
Design
43 Inadequate design-team experience
Design
44 Un-use of advanced engineering design software
Design
45 Shortage of construction materials in market
Materials
46 Changes in material types and specifications during construction
Materials
47 Delay in material delivery
Materials
48 Damage of stored material while they are needed urgently
Materials
49 Delay in manufacturing special building materials
Materials
50 Late procurement of materials
Materials
51 Late in selection of finishing materials due to availability of many types in market
Materials
52 Equipment breakdowns
Equipment
53 Shortage of equipment
Equipment
54 Low level of equipment-operator's skill
Equipment
55 Low level of equipment-operator's skill
Equipment
56 Lack of high-technology mechanical equipment
Equipment
57 Shortage of labours
Labors
58 Unqualified workforce
Labors
59 Nationality of labours
Labors
60 Nationality of labours
Labors
61 Personal conflicts among labours
Labors
62 Effects of subsurface conditions (e.g., soil, high water table, etc.)#p#分頁標(biāo)題#e#
External
63 Effects of subsurface conditions (e.g., soil, high water table, etc.)
External
64 Hot weather effect on construction activities
External
65 Hot weather effect on construction activities
External
66 Unavailability of utilities in site (such as, water, electricity, telephone, etc.)
External
67 Effect of social and cultural factors
External
68 Traffic control and restriction at job site
External
69 Accident during construction
External
70 Differing site (ground) conditions
External
71 Changes in government regulations and laws
External
72 Delay in providing services from utilities (such as water, electricity)
External
73 Delay in performing final inspection and certification by a third party
External
The red book provides procedures for claim announcement and to be followed by the contractor. Clauses which expressly provide procedure for claims notification and particularization which are as follows
* 6.3 Notice of delay or disruption in case of delayed information or instructions:
* 12.2 Notice of adverse physical obstructions or conditions
* 30.3 Notice of damage to any bridge or road due to the transport of materials or plant
* 38.1 Notice of when any part of the works or foundation is ready to be covered up (compliance required for 38.2 to apply.
* 40.3 Notice requesting permission to proceed with work after a suspension lasting more than 84 days (Compliance required for 51.1 to apply.
* 42.1 Notice containing “reasonable proposal” regarding access and possession ( Compliance required - arguably - for 42.2 to apply);
* 44.2 Notice of an application for an extension of time:
* 52.2 Notice to claim additional payment for varied work
* 53.1 Notice to claim additional payment “ under any clause of these conditions or otherwise”
* 65.5 Notice of increased costs arising from special risk
* 69.4 Notice of suspension by the contractor due to non payment by engineer
2.5 Establishing Entitlement - the legal basis for claims under FIDIC condition of contract
All mainstream forms of contract used in the construction and engineering industries contain contractual machinery to deal with claims for extensions of time and additional cost. FIDIC red book 4th edition contains the following provisions allowing recovery of additional cost in specified circumstances including the following;
Clauses 6.3/6.4 : Engineers failure to issue drawings or instructions within a reasonable time of the Contractor giving notice of their requirement.
Clause 12.2 : Contractor encountering physical obstructions or conditions not reasonably foreseeable by an experienced Contractor.#p#分頁標(biāo)題#e#
Clause 27.1 : Instructions relating to discovery of fossils/antiquities etc.
Clause 31.2 : Contractor makes facilities available to others working on site.
Clauses 36.5, 38.2 : Contractor incurs costs testing or uncovering works and such tests or uncovering shows that the Contractor's works were not defective.
Clause 40.2 : Contractor is instructed to suspend the works.
Clause 42.2 : The Employer fails to provide access in accordance with the requirements of the contract/programme.
Clause 51 : Variations are ordered
In addition Clause 44.1 cites certain other circumstances that may entitle the Contractor to more time, including adverse weather, and provides the machinery by which the Engineer has to extend the time for completion. Clause 44.1 is closely inter-linked with clause 47.1 which provides that the Contractor shall pay liquidated damages at the agreed rate in the event of failure to complete on time.
The Red Book ( 4th Edition) provides in certain circumstance a contractor's entitlement to claim may be lost if he fails to give notice of his intention to claim or fails to provide detailed claim particulars within the time scale prescribed. There are two provisions of the red Book ( 4th Edition) which states that a failure to comply with the specified notice or particularization produces for making a claim will satisfy the rejection of claim. First, clause 44.2, which is concerned with applications for extension of time, This clauses provides that in case of noncompliance with time limit to provide notice and/or to provide detailed claim particulars, the engineer “ is not bound to make any determination” of a claim for an extension of time.
The engineer, therefore, has discretion not to make a determination if either the time limit for notice or for particularization is not met. Second, Clause 52.2 which applies to application for payment for variations, This clauses states that the varied work will not be valued unless notice of an intention to claim extra payment is made within 14 days of the date of the instruction. This clause allows for a claim to be disallowed if the 14 days time is not complied with. All claims for additional payment under the Red book ( 4th Edition) require 28 days notice from the date of the event giving rise to the claim. The following suggest the procedure for the claim under clause 53.3. 1 shows claim procedure under FIDIC condition of contract.
2.6 How to evaluate the financial amount
The principles behind an additional cost claim are simply that due to events and circumstances for which the other party is responsible, execution of the Works became more difficult than foreseen and/or the period for completion of the Works is longer. Valuation of claims associated with delays and disruption which suffered by a Contractor and the sorts of loss and expense to which the Contractor is entitled.#p#分頁標(biāo)題#e#
Costs for delay and disruption consist of the following:
1. Additional expenditure
2. Interest and Finance Charges
3. Loss of Productivity
4. Inflationary Cost Increases
5. Site Overheads
6. Off-site or Head Office Overheads
7. Loss of Profit
3 Previous studies on the issues of problems which generate claims
3.1 Identifying potential contract problems
While there are numerous items and services that can be purchased, each purchase of goods and services faces the same set of contractual risks that affect the successful accomplishment of any of the 5 “R's”. Abi-Karam (2002) suggested that every purchase should be evaluated for six types of risks: Proposal risk, Surety and liability risks, Schedule risk, Contractual risk, Performance risk and Price risk.
Davison and Wright (2004) expanded on the definition of these risks to include their relationship to the following five “R's”:
Proposal risk: The legal document that defines the item or service procured (the right item), the mutual areas of agreement, and how risks will be allocated and rewarded.
Surety and liability risks: Protection of the agency's financial and legal interests (the right price). The contract will define the insurance requirements, bonding requirements, and licensing that are necessary to protect the agency in the event of contract termination or to meet statutory requirements.
Schedule risk: Ensuring timely delivery (the right time). The contract will contain clear and specific language describing the contract deliverables, delivery terms, and any penalties for late delivery.
Contractual risk: Establishing change order procedures, dispute resolution process and termination procedures (the right price and time).The contract is a living document and allowances must be made to accommodate unforeseen conditions that may affect the purchase. The contract will specify who has the authority to make changes, how changes will be made, and what changes will be unilateral. The contract will specify how disputes will be resolved if mutual agreement cannot be reached. The contract will specify the termination process.
Performance risk: Defining acceptance (the right quality). The contract will define the conditions under which acceptance will occur and what type of inspection will be required.
Price risk: Defining payment terms (the right price). The contract will define how and when the Contractor will be paid. Based on observation and communication with peers, Davison and Wright (2004), proposed that each of these six contractual risks is comprised of a set of contract problems that may occur each time the good or service is procured (Table 2 shows the types of contract administration problem). Each contract problem that occurs can threaten the success of the project by impacting any or all of the 5 “R's” in an adverse manner, such as, delivery of incorrect product, incorrect quantity, an increase in project costs, a delay in delivery, poor quality or the ultimate unsuccessful result, contract termination.#p#分頁標(biāo)題#e#
TABLE 2 - CONTRACT ADMINISTRATION PROBLEM WITH EXAMPLES
Sr No
Contractual Risk and Contractual Problem
Example
1 Proposal risk: Unclear scope of
Work
Ambiguous specifications lead to disputes over required performance, acceptance.
2 Surety and Liability risk: Increased
Cost
Inadequate bonds and insurance to cover vendor failure
3 Schedule risk: Wrong product
Purchase order or contract clearly identifies correct product, but vendor ships incorrect. No dispute involved
4 Schedule risk: Delay
Purchase order has clearly stated completion date. Completion date delayed (any length of time) due to agency or vendor (with or without cause).
5 Contractual risk: Change order
Change in the scope of work (additional work, money, time), after contract award. Can be requested by either party for any reason
6 Contractual risk: Dispute
resolution and personality conflict
Personality conflicts between agency project manager or staff and vendor project manager or employees. Disagreement between the parties that cannot be easily resolved. May involve scope of work, materials supplied, payment schedules, or any other aspect of the contract.
7 Performance risk: Definition of
Acceptance
Completion of project is delayed due to non acceptance of final product. Example: difference in either party's definition of what was supposed to be
delivered or provided
8 Performance risk: Poor
Performance
Contract clearly states a level of expected performance (this is not in dispute) and quality problems with vendor's performance of work occur.
9 Performance risk: Sub Contractors
The vendor uses subcontractors not on his payroll to perform any or all of the work. Prior approval, for use of subcontractors, was received
10 Performance risk: Other sources
There are very few vendors that can perform the work
11 Performance risk: Risk of failure
The project has a high risk of failure. i.e. New technology, new equipment, new vendor, Project never been done before. Tight timeline or budget
12 Price Risk: Cost
Project has a high cost.
[Source Journal of management research ISSN 1941 -899X 2009 , Vol 1 No 2: E2]
According to Mohamad Ibrahim Mohamad Zulkifli Madon, Rosli Zin, Shaiful Amri Mansuri , the constructions contracts express the intent of parties and memorialize their principal risk allocation decisions (McCallum, 2002). To understand the contract requirements is to understand the contents of the documents and the spirit of the contractual relationships.
Contracts are formed and signed based on the fair basis where parties agree amicably to discharge their obligations to satisfy each other needs and requirements. Indeed as construction are a complex and challenging process, it requires interpretation of conformance with myriad laws, code and regulations, marshalling of considerable resources including labor, equipments, materials and good communication and coordination among multiple parties involved in the project (Dennis, 1982). Many factors are unknown or unknowable at the start of any project.#p#分頁標(biāo)題#e#
This detail understanding of the whole requirements and process of the contract are essential in order to minimize the construction risks that may lead to unnecessary problems such as disputes, claims, litigation, shoddy works, and reworks even lost of future business relations. The effects of construction disputes are detrimental. If disputes are not properly managed, they may cause project delays, undermine team spirit, increase project costs, and, above all, damage continuing business relationships.
The proper allocation of responsibilities is a crucial factor in determining whether a particular construction contract should be considered ‘a good' contract. Mc Callum (2002) characterized a good contract clearly informed such party what it must do and to what it is entitled. It also informs each party of its right if the other party does not performed as pronounced. It anticipates the likely problems and resolves them clearly and in a way strikes the parties as a proper allocation of risks and responsibilities. A good construction contract of course, includes well drafted drawings and specifications that inform the contractors what he must do to earn the promise compensation and provide a method of determining whether the objective has been reached.
According to them factors which improve understanding of contract document are
* Sincerity in contracting
* Drawing must be clear and checked by all parties.
* Clarity in contract document for better understanding toward contract documents.
* Client's requirements must be clearly understood.
* Contract document should be written in simple language.
* Establish good communication relationship.
* Contract document must be precise, objective and practical
* Qualified personnel to prepare the contract document.
* Regulatory requirement to be clearly explained.
* Bill of Quantities to be clearly and objectively detailed.
* Minimize use of complicated legal phrases.
* Provide well trained personnel for every project to interface the contract.
* General condition of the contract to be made familiar
* Construction work specifications to be simple and suit class of contractor.
* Mandatory induction session for a contractor before any contract to be
Essam K Zaneldin suggests claims are becoming a way of life and indeed, an impossible part of modern contract system. In UAE construction claims normally seen in almost every construction project, are direct results of the ongoing growth in the construction industry in the country In general claims are common in construction projects and can happen as a result of several reasons that can contribute to delaying a project and increasing its cost.
Finishing a project on schedule is a difficult task to accomplish in the uncertain, complex, multiparty, and dynamic environment of construction projects. To enhance the chances of success contractor submitting claims most closely follow the steps stipulated in the contract condition and present sufficient documentation. He carried out the study of types, causes, frequency of construction claims in the emirates of Dubai and Abu Dhabi in UAE using a data from 124 claims for a verity of projects in the two emirates. As per his analysis one of the problem area is the change type of claims was the most frequent types of claims, Extra work types of claims are second and contract ambiguity remain ranked third. He also conclude that change order are the most frequent causes of claims while delay caused by owner ranked second and planning error ranked at third position.#p#分頁標(biāo)題#e#
Dr Ayman H Al Momani carried out a quantitative analysis on construction delay in Jordan. The objective of study was determining the causes and level of time extension of public project and to aid construction managers in establishing adequate prior to the contract award using quantitative data. The key task was to design research so that the information obtained permits the assessment of their impact. Therefore the best approach to assessing the potentials is to adopt randomly selected samples. The sampling population was established by selecting 130 public project constructed in different regions of Jordan during the period of 1990 - 97. The data was found in the contract files of several state agency.
Data collected were of 5 kinds of public projects Residential houses of public s, office and administrative buildings, school buildings, medical centers and communication facilities. The result of this study indicated that the main causes of delay in construction of public projects were related to Designers, user changes, weather, site condition, late deliveries, economic conditions, and increase in quantity.
K C Iyer, N.B Chaphalkar, G A Joshi suggest most of the construction projects are executed through contracts which are generally not easy to comprehend even by professionals. Advancement in technology and mammoth requirement of infrastructure in developing countries like India, there has been increase in size and complexities in the nature of projects. This gives rise to further ambiguities in the prevailing contract forms eventually making contract forms more complex and difficult and causing adversarial impacts such as increase in number and frequency of claims and disputes besides time and cost overruns. To overcome the worsening scenario, they develop a system that can assist the contract administrators to understand and evaluate worth of their claims prior to taking it to litigation
Many construction disputes can be avoided by careful planning during contract formation. The specific terms and concepts below, which are used in contract drafting, are very important factors for avoiding future problems of claims
(A) Incorporation by reference
(B) Scope of work
(C) Right to stop work
(D) Payment
(E) Exculpatory clauses
(F) Notice
(G) Warranties
(H) Termination for cause and convenience
(I) change orders and changed conditions, and
(J) pay-if-paid and pay-when-paid clauses
Ustinovichius L, Andriuškevichius A, Kutut V, Migilinskas D Barvidas A. analyse construction contract provided by FIDIC and determine there effectiveness by verbal methods. According to him contractors of international construction projects are often faced with complicated situations working in the condition of uncertainty in construction. One of the potential risk factors is associated with the requirement of contract condition. He used a simple quantitave method for evaluating the requirements defined in specifications of the contract.#p#分頁標(biāo)題#e#
According to them effectiveness of construction contract can be evaluated based on the following factors
Technical Specification
Cost
Terms of Payment
Schedule
Performance Guaranty
Warranty
Liability
Insurance Cost
Liability Limit
Assaf et al (Assaf SA, Alkhalil M, AL-Hazmi M. 1995) identified the 56 main causes of delay in Saudi large building construction projects. The scope of their research was limited to large public building projects in the eastern province of Saudi Arbia. Large building project include projects that are more than 10,000,000 Saudi riyals (SR) Based on their survey
Based on the contractors surveyed the most important delay factors are
1. Preparation of approval of shop drawings
2. Delay in contractors progress
3. Payment by owner and design changes
From the view of architect and engineer
1. Cash problem during construction
2. The relation ship between subcontractors
3. Slow decision making process by the owner
However, Owner agreed that
1. The Design error
2. Labor shortage
3. Inadequate labor skills
These are the important issues which initiate claim.
Ogunlana and Promkuntong ( OgunlanabS O and Promkuntong K. 1996) conducted study on construction delay in Thailand this paper repots on a study of construction delay experienced during the period, especially in 1992 when the boom was diminishing. The major sources of the delay on high rise building construction project are identified and a comparison with other studied is made to determine if there are special project management problem in developing economies. They found that the problem faced by the construction industry in developing economies like Thailand could be:
Storage and inadequacies in industry/environment infrastructure (mainly supply of resources)
* Shortage of resources
* Unavailability of subcontractors
· Transportation problems
2. Causes by client
* Financial difficulties of owners
3. Caused by contractors incompetence
* Poor contract management, planning and scheduling deficiencies
* Unreasonable low bidding
* Contractors financial difficulties
They recommended that there should be concerted concerted effort by economy managers and construction industry associations to provide the necessary infrastructure for efficient project management.
Dr. Edwin H.W. Chan* and Henry C.H. Suen carried out study on Legal Issues of dispute management in International construction project contracting. According to them contracting parties in international project have to develop ways to respond to the various legal obligations and practice by the international conventions and national authorities and, at the same time, to avoid and resolve disputes arising from legal issues. In light of this, they provide a source of reference for contracting parties to identify those legal issues that are related to dispute management, which includes avoiding and resolving disputes in international construction. In doing so, they carried out an in-depth literature review of previous research studies and face-to face interviews with practitioners in the industry.#p#分頁標(biāo)題#e#
They made discussion on the significant issues as follows
Harmonization of construction law
Law of dispute management
Interpretation if international construction contract
Disputology in construction industry.
Causes of Disputes
Causes of disputes over delay identified by Assaf et al. includes: shortage of construction material, changes in types and specifications during construction, slow delivery of material, damage of material in storage, delay in the special manufacture of the building material, shortage of labour, labour skills, nationality of labourers, equipment failure, equipment shortage, unskilled operators, slow delivery of equipment, equipment productivity, financing by Contractor during construction, delays in Contractor's progress payment by Owner, cash problems during construction, design changes by Owner or his agent during construction, design errors made by designers, foundation conditions encountered in the field,
Mistake in soil investigation, water table conditions on site, geological problems on site, obtaining permits from municipality, obtaining permits for labourers, excessive bureaucracy in project Owner operation, building code used in the design of the project, preparation and approval of shop drawings, waiting for sample material approval, preparation of scheduling networks and revisions, lack of training personnel and management support, lack of database in estimating activity duration and resources, judgment of experience in estimating time and resources, project delivery systems used, hot weather effect on construction activities, insufficient available utilities on site, the relationship between different subcontractor's schedule,
The conflict between the consultant and the Contractor, uncooperative Owners, slowness of the Owner decision making process, the joint ownership of the project, poor organization, insufficient communication between Owner and designer at the design phase, unavailability of professional construction management, inadequate early planning of the project, inspection and testing procedures used in the projects, errors committed during field, application of quality control based on foreign specification, controlling subcontractors by general Contractors in the execution of the works, the unavailability of financial incentives for Contractor to finish ahead of schedule, negotiations and obtaining of contracts, legal disputes between various parties, social and cultural factors, accidents during construction .
Through a questionnaire survey conducted on 61 contemporary construction projects in Hong Kong Kumaraswamy [8] attempts to better understand disputes; he identifies common root causes, proximate causes and confirms the need of further studies to isolate the real root causes of avoidable claims and disputes. A list of the root causes and the proximate causes is shown in 2. (Grace Younis, Geraed Wood, M. Asem Abdul Malak,)#p#分頁標(biāo)題#e#
Unfair risk allocations
Unclear risk allocation
Unrealistic time/cost quality targets
Uncontrollable external event
Adverse culture
Unrealistic tendering price
Inappropriate contract price
Lack of competence of of project participant
Lack of professionalism of project participant
Client lack of information
Unrealistic information expectation
Inadequate brief
Poor communication
Personality clashes
Vested interest
Changes by client
Slow client respond
Exaggerated claims
Estimating error
Others e.g. work error
Internal disputes
Inadequate contract administration
Inaccurate design information
Incomplete tender information
Inadequate design document
Inappropriate contractor selection
Inappropriate payment modalities
Inappropriate contract form
( Sources - Minimizing Construction Disputes: The reletationship between risk allocation and behavioural attitudes by Grace Younis, Geraed Wood, M. Asem Abdul Malak
TABLE 3 - CATEGORIZING CAUSES OF DISPUTES
1 Al Momani
Causes of delay: poor design, change orders, weather, site conditions, late delivery, economic conditions, and increase in quantity.
2 Alkass et al.
Strikes, rework, poor organization, material shortage, equipment failure, change orders, act of God.
3 Bristow and Vasilopoulous
Five areas unrealistic expectations: contract documents, communication lack of team spirit and change.
4 Colin et al.
Six areas: payment, performance, delay, negligence, quality and administration.
5 Diekmann et al.
Three areas: people, process and product.
6 Heath et al.
Seven areas: contract terms, payment, variation, time nomination, re-nomination and information.
7 Hewit
Six areas: change of scope change conditions, delay, disruption, acceleration and termination.
8 Kululanga et al.
Four sources of dispute: (1) errors, defects and omissions in the contract documents, (2) underestimating the real cost of the project in the beginning, (3) changed conditions and (4) stakeholders involved in the project.
9 Madden
Three categories: legal, technical and quantum.
10 Molenaar et al.
Three categories: people issue, process issue and project issues.
11 Rhys Jones
Ten areas: management, culture, communications, design, economics, tendering pressures, lay, unrealistic expectations, contracts and workmanship.
12 Semple et al.
Four areas: acceleration, access, weather, and changes
13 Sykes
Two areas: misunderstandings and unpredictability
( Sources - Minimizing Construction Disputes: The reletationship between risk allocation and behavioural attitudes by Grace Younis, Geraed Wood, M. Asem Abdul Malak)#p#分頁標(biāo)題#e#
3.2 As per the literature review the common issues which arises claims are as follows
1) Issues arises normally causes by the client
* Awarding contract to lowest bid
* Suspension of works
* Unrealistic imposed contract duration
* Slow decision making by owners
* Owner interference
* Finance and payment of completed work
2) Issues arises normally by the contractor
* Poor site management and supervision
* Improper planning
* Mistake during construction
* Contractors financial problem
* Bad quality of contractors work
* Subcontractors problem
* Construction method
* Low price of contract due to high competition
3) Issues arises normally by consultant
* Poor contract management
* Delay in the design information and approval of drawing
* Delay in testing and inspecting the product
* Discrepancies in contract document
* Poor management in Quality assurance control
4) Issues arises due to material
* Quality of material
* Shortage of material;
5) Issues due to by Labor & Equipment
* Equipment availability and failure
* Change in material and labor cost
* Labor productivity
6) Issues due to Contractual relationships
* Lack of communication between parties
* Impropriate overall organizational structure linking of all parties to the project
* Major disputes and negotiation
* Third party delay
7) Claims that are normally caused by External factors
* Weather condition
* Regulatory changes and building code
* Problems with neighbors
* Unforeseen ground condition
* Accidents
* Adverse site condition
8) Issues arises are normally by political and social
* Changes in laws and regulations
* Public disorder
* Labour disputes and strikes
9) Issues arises normally by economy
* Inflation
* Availability of labour and equipment
3.3 For the purpose of study and based on the above literature review the issues are categorized in following manner
SITE ISSUES
Adverse site conditions
Necessary approvals may not be obtained or may be obtained only subject to unanticipated condition
Archeological and cultural heritage discoveries
No proper access to the site
Project site may be subject to invalidity of approval
Any environmental issue which leads delay and additional cost. E.g. Non stop rain and high wind speed.
DESIGN CONSTRUCT AND COMMISIONING ISSUES#p#分頁標(biāo)題#e#
1. Design of the facility is incapable of delivering the service at anticipated cost
2. Construction events occur during construction which prevent the facility being delivered on time and on cost
Commissioning tests which are required to be completed for the provision of services to commence, cannot be successfully completed
Design co-ordination on design and construct basis project.
SPONSOR AND FINANTIAL ISSUES
Interest rate may move adversely and affect the bid price
Failure of sponsor to finance the project because of economic crises
Change in tax policy by government before and after the completion of project
Financial problem arises due to change in ownership
OPERATING ISSUES
Require cost is more than anticipated with an inadequate quality
Design and construction quality is inadequate resulting higher maintenance and refurbishment cost
Change in output specification outside the agreed range
Subcontractor fails to provide the required service.
POLITICAL AND SOCIETAL
Change in law policy during the course of project
Change in regulations during the course of project
Additional approval require during the course of the project which it outside the contract
Labour dispute and strike
EXCULPATARY CLAUSES ISSUES
No damage of delay
Site inspection before the award of contract
Liquidation Damages
Indemnity Clauses
References:
Grace Younis, Geraed Wood, M. Asem Abdul Malak , Minimizing Construction Disputes: The relationship between risk allocation and behavioral attitudes
Jon Murdoch and Will Hughes (2000), Construction contracts Law and Management. Third Edition. Spon Press
Sadi A. Assaf, & Sadiq Al-Hejji. (2005) Causes of delay in large construction projects. International Journal of Project Management 24 (2006) 349-357.
Essam K. Zaneldin. (2006) Construction claims in United Arab Emirates: Types, causes, and frequency. International Journal of Project Management 24 (2006) 453-459.
Ayman H. Al-Momani. ( 2000) Construction delay: a quantitative analysis. International Journal of Project Management 18 (2000) 51-59
M.Asem U. Abdul-Malak, & A.M.ASCE, & Mustafa M. H. EL-Saadi, & Marwan G. Abou-Zeid. (2000). Process Model for administrating Construction Claims. Journal of Construction Engineering and Management 18 (April 2002) 84-94.
K.C. Iyer, & N.B. Chaphalkar , & G.A. Joshi. (2007) Understanding time delay disputes in construction contracts. International Journal of Project Management 26 (2008) 174-184.
Ustinovichius L, Andriuškevichius A, Kutut V, Migilinskas D Barvidas A, Verbal analysis of engineering and construction contract.#p#分頁標(biāo)題#e#
Dr Edwin H.W. Chan and Henery C.H. Suen , Legal issues of disputes management in international construction project contracting, Construction Law Journal, Feb 2004.
Ogunlana S O, Promkuntong K, Construction delay in a fast growing economy: Comparing Thailand with other economies. Intentional Journal of Project Management 1996:14(1): 37-45.
Mohammad Ibrahim Mohammad, Zulkifli Madon Rosli Zin Shaiful Amri Mansuri, Clarity and improving level of understanding of contract documentation, Malaysian Journal of civil Engineering 20 (1) : 128 - 136 (2008)
Bill Devidsons, Richard J Sebastain, An analysis of the Consequences of Contract administration problem for contract types. Journal of management research ISSN 1941 -899X 2009, Vol 1 No 2: E2
Nael Bunni, The FIDIC Forms of contract, Third edition, Blackwell Publishing
E.C Corbett, (1991) FIDIC 4th A practical legal guide, Sweet c Maxwell publication
Jon Murdoch and Will Hughes (2000), Construction contracts Law and Management. Third Edition. Spon Press
相關(guān)文章
UKthesis provides an online writing service for all types of academic writing. Check out some of them and don't hesitate to place your order.